View IFT /PQ / REOI / RFP / PPS Notice Details

Ministry :	Ministry of Water Resources	Division :
Organization :	Bangladesh Water Development Board (BWDB)	Procuring Entity Name :	Bagerhat WD Division
Procuring Entity Code :		Procuring Entity District :	Bagerhat
Procurement Nature :	Works	Procurement Type :	NCT
Event Type :	TENDER	Invitation for :	Tender - Single Lot
Invitation Reference No. :	42.01.0100.617.000.44.0001.26-555;Date:20/09/2026	Tender/Proposal Status :	Amendment/Corrigendum issued : 1
App ID :	230337	Tender/Proposal ID :	1337238

Key Information and Funding Information :

Procurement Method :	Open Tendering Method (OTM)	Budget Type :	Development
Source of Funds :	Government

Particular Information :

Project Code :	224363200	Project Name :	Protection of Morrelganj Upazila Sadar and adjacent areas from erosion of Pangusi river in Bagerhat District and Re-excavation/Dredging of Bishkhali river
Tender/Proposal Package No. and Description :	DB-01 River Bank protection work (Precautionary) from km 14.500 to km 14.800 = 300 m at Debraj of Doiboggohati Sub-Project along the Left Bank of Panguchi River in C/W "Protection of Morrelganj Upazila sadar & Adjacent Areas from Erosion of Panguchi River & Re-excavation/Dredging of Bishkhali River in Bagerhat District " under Bagerhat WD Division, BWDB, Bagerhat.
Category :	Construction work for water projects; Works for complete or part construction and civil engineering work;
Scheduled Tender/Proposal Publication Date and Time :	21-Sep-2026 14:00	Tender/Proposal Document last selling / downloading Date and Time :	18-Oct-2026 16:00
Pre - Tender/Proposal meeting Start Date and Time :	21-Sep-2026 14:20	Pre - Tender/Proposal meeting End Date and Time :	21-Sep-2026 17:00
Tender/Proposal Closing Date and Time :	19-Oct-2026 16:00	Tender/Proposal Opening Date and Time :	19-Oct-2026 16:00
Last Date and Time for Tender/Proposal Security Submission :	19-Oct-2026 15:30

Information for Tenderer/Consultant :

Eligibility of Tenderer :	As stated in detail in ITT and TDS.
Brief Description of Works :	DB-01 River Bank protection work (Precautionary) from km 14.500 to km 14.800 = 300 m at Debraj of Doiboggohati Sub-Project along the Left Bank of Panguchi River in C/W "Protection of Morrelganj Upazila sadar & Adjacent Areas from Erosion of Panguchi River & Re-excavation/Dredging of Bishkhali River in Bagerhat District " under Bagerhat WD Division, BWDB, Bagerhat.
Evaluation Type :	Lot wise
Document Available :	Package wise
Document Fees :	Package wise
Tender/Proposal Document Price (In BDT) :	4000
Mode of Payment :	Payment through Bank
Tender/Proposal Security Valid Up to :	16-Mar-2027
Tender/Proposal Valid Up to :	16-Feb-2027

Lot No.	Identification of Lot	Location	Tender/Proposal security (Amount in BDT)	Tentative Start Date	Tentative Completion Date
1	River Bank protection work (Precautionary) from km 14.500 to km 14.800 = 300 m at Debraj of Doiboggohati Sub-Project along the Left Bank of Panguchi River in C/W "Protection of Morrelganj Upazila sadar & Adjacent Areas from Erosion of Panguchi River & Re-excavation/Dredging of Bishkhali River in Bagerhat District " under Bagerhat WD Division, BWDB, Bagerhat.	Debraj ,Morrelganj,Bagerhat	1850000	25-Nov-2026	30-Jun-2027

Procuring Entity Details:

Name of Official Inviting Tender/Proposal :

JAYANTU PAUL

Designation of Official Inviting Tender/Proposal :

Executive Engineer

Address of Official Inviting Tender/Proposal :

Address	: Bagerhat
City	: Bagerhat
Thana	: Bagerhat Sadar
District	: Bagerhat - 9300
Country	: Bangladesh

Contact details of Official Inviting Tender/Proposal :

Phone No	: 0468-62195
Fax No	:

The procuring entity reserves the right to accept or reject all Tenders/Proposals / Pre-Qualifications / EOIs

Note: Bank will update the payment transactions only at the end of the day, so the tenderers should make sure the securities and other payments are made at least one day before the submission date.

Documents

Amendment / Corrigendum No. : 1
Amendment / Corrigendum Text :	Corrigendum issues required.

Field Name

Old Value

New Value

Document last selling date & time

13/10/2026 16:50

18/10/2026 16:00

Eligibility of Consultant

As stated in detail in ITT and TDS.

Location(Lot No : 1)

Debraj ,Morrelganj

Debraj ,Morrelganj,Bagerhat

Opening Date & Time

14/10/2026 15:00

19/10/2026 16:00

PCC 1. Definitions
(aa)Intended Completion Date

The Intended Completion Date for the whole of the Works shall be 2027-06-30

PCC 1. Definitions
1.1(qq)Start
Date

The Start Date shall be 2026-11-15

The Start Date shall be 2026-12-02

PCC 1. Definitions
1.1(uu)Works

Works
The Works consist of River Bank protection work (Precautionary) from km 14.500 to km 14.800 = 300 m

Works
The Works consist of River Bank protection work (Precautionary) from km 14.500 to km 14.800 = 300 m at Debraj of Doiboggohati Sub-Project along the Left Bank of Panguchi River

PCC 13. Possession of the Site
13.1 Possession of the Site

Name of the Parts of Works	Possession Dates
River Bank protection work (Precautionary) from km 14.500 to km 14.800 = 300 m at Debraj of Doiboggohati Sub-Project along the Left Bank of Panguchi River in C/W "Protection of Morrelganj Upazila sadar & Adjacent Areas from Erosion of Panguchi River & Re-excavation/Dredging of Bishkhali River in Bagerhat District " under Bagerhat WD Division, BWDB, Bagerhat.	2026-11-04

Name of the Parts of Works	Possession Dates
River Bank protection work (Precautionary) from km 14.500 to km 14.800 = 300 m at Debraj of Doiboggohati Sub-Project along the Left Bank of Panguchi River in C/W "Protection of Morrelganj Upazila sadar & Adjacent Areas from Erosion of Panguchi River & Re-excavation/Dredging of Bishkhali River in Bagerhat District " under Bagerhat WD Division, BWDB, Bagerhat.	2026-11-29

PCC 2. Interpretation
2.5. Sectional completion

Name of the Parts of Works	Sectional Commencement Dates	Sectional Completion Dates
River Bank protection work (Precautionary) from km 14.500 to km 14.800 = 300 m at Debraj of Doiboggohati Sub-Project along the Left Bank of Panguchi River in C/W "Protection of Morrelganj Upazila sadar & Adjacent Areas from Erosion of Panguchi River & Re-excavation/Dredging of Bishkhali River in Bagerhat District " under Bagerhat WD Division, BWDB, Bagerhat.	2026-11-08	2027-05-27

Name of the Parts of Works	Sectional Commencement Dates	Sectional Completion Dates
River Bank protection work (Precautionary) from km 14.500 to km 14.800 = 300 m at Debraj of Doiboggohati Sub-Project along the Left Bank of Panguchi River in C/W "Protection of Morrelganj Upazila sadar & Adjacent Areas from Erosion of Panguchi River & Re-excavation/Dredging of Bishkhali River in Bagerhat District " under Bagerhat WD Division, BWDB, Bagerhat.	2026-12-02	2027-06-20

PCC 39. Commencement of Works
39.1 Commencement of Works

Commencement Date of Works: 2026-11-01

Commencement Date of Works:2026-11-25

PCC 41. Programme of Works
41.2 Programme Update

The period between Programme updates is 15

The period between Programme updates is 30

PCC 41. Programme of Works
41.3 Withhold amount

The amount to be withheld for late submission of an updated Programme is 2000.000

The amount to be withheld for late submission of an updated Programme is 20000

PCC 64. Payment Certificates
64.5 ES obligations withheld maximum Amount Percentage

The maximum amount of payment withheld of forfeited due to failure in compliance with ES Specifications is 0.000 percent of the final Contract Price of the whole of the Works.

The maximum amount of payment withheld of forfeited due to failure in compliance with ES Specifications is 2 percent of the final Contract Price of the whole of the Works.

PCC 82. As-built Drawings and Manuals
82.1 As-built drawing date

The date by which ?as-built? drawings are required	The date by which operating and maintenance manuals are required
2027-07-07	2027-07-10

The date by which ?as-built? drawings are required	The date by which operating and maintenance manuals are required
2027-07-07	2027-07-10

PCC 9. Eligibility
9.1 Contractor nationality

Countries are not eligible
Any bidder, firm, or entity originating from a country that does not maintain diplomatic relations with the People"s Republic of Bangladesh shall not be eligible to participate in this tender

Countries are not eligible
Tenderers from the following countries are not eligible: ISRAEL.

PCC 9. Eligibility
9.2 Origin Countries

Country of origin are not eligible
All materials, equipment, plant, and supplies originating from countries that do not maintain diplomatic relations with the Peopleâ??s Republic of Bangladesh shall not be eligible for use under this Tender.

Country of origin are not eligible
Materials, Equipment and associated services from the following countries are not eligible: ISRAEL.

Last date & time for Tender/Proposal Security Submission

14/10/2026 14:30

19/10/2026 15:30

Start Date(Lot No : 1)

01/11/2026

25/11/2026

Closing Date & Time

14/10/2026 15:00

19/10/2026 16:00

TDS/PDS--A. General--

The PE is Executive Engineer, Bagerhat WD Division, BWDB, Bagerhat.
Telephone:0468-62195
e-mail address: xen.bwdb.bagerhat@gmail.com

The Name of the Tender is:River Bank protection work (Precautionary) from km 14.500 to km 14.800 = 300 m at Debraj of Doiboggohati Sub-Project along the Left Bank of Panguchi River in C/W "Protection of Morrelganj Upazila sadar & Adjacent Areas from Erosion of Panguchi River & Re-excavation/Dredging of Bishkhali River in Bagerhat District " under Bagerhat WD Division, BWDB, Bagerhat.

Tender Ref: 42.01.0100.617.000.44.0001.26-555;Date:20/09/2026

Lot No(s):DB-01

[if there is more than one(1) lot, individual lots are to be identified in conformity with Section 6: Bill of Quantities]

The PE is Executive Engineer, Bagerhat WD Division, BWDB, Bagerhat.
Telephone:0468-62195
e-mail address: xen.bwdb.bagerhat@gmail.com

Tender Ref: 42.01.0100.617.000.44.0001.26-555; Date:20/09/2026

Lot No(s):DB-01

TDS/PDS--B. e-Tender Document (e-TD)--

The following are authorised agents/offices of the Procuring Entity for the purpose of issuing the Tender Document:
Office address of the PE
Address:The PE is Executive Engineer, Bagerhat WD Division, BWDB, Bagerhat.
Telephone:0468-62195
e-mail address: xen.bwdb.bagerhat@gmail.com Telephone/Cell

e-mail address:

Office address of Agent(s)

Address:

Telephone No.:

e-mail address:

[If not applicable, please specify “None”. If there is more than one (1) Agent office, then list all Agent’s office names and contact details]

TDS/PDS--B. e-Tender Document (e-TD)--

For clarification of Tender Document purposes only, the Procuring Entity’s address is:The PE is Executive Engineer, Bagerhat WD Division, BWDB, Bagerhat.
Telephone:0468-62195
e-mail address: xen.bwdb.bagerhat@gmail.com

For clarification of Tender Document purposes only, the Procuring Entity’s address is: Office of the Executive Engineer, Bagerhat WD Division, BWDB, Bagerhat.
Telephone:0468-62195
e-mail address: xen.bwdb.bagerhat@gmail.com

TDS/PDS--C. Qualification Criteria--

The minimum specific experience as a Prime Contractor or Subcontractor or ManagementContractor in construction works under public sector of at least onecontract(s) ofConstruction/Repair of revetment/river bank protection work/shore protectionwork/crossbar/Spur/groyne successfully completed within the last 5 years, each with a value of at least Tk. 55600000.00 BDT (Five Crore Fifty-Six Lakh Taka Only)); years counting backward from the date of publication of IFT in the newspaper]

The minimum specific experience as a Prime Contractor or Subcontractor or ManagementContractor in construction works under public sector of at least onecontract(s) of Construction/ Repair of revetment/ River bank protection work/ Shore protection work/ Crossbar/ Spur/ Groyne successfully completed within the last 5 years, each with a value of at least Tk. 5,50,00,000.00 (Five Crore Fifty Lakh Only); years counting backward from the date of publication of IFT in the newspaper]

TDS/PDS--C. Qualification Criteria--

The required average annual construction turnover under public sector shall be greater than Tk. 111300000.00 BDT ( Eleven Crore Thirteen Lakh Taka Only) over the best three (3) years in the last five (5) financial years.

The required average annual construction turnover under public sector shall be greater than Tk. 11,00,00,000.00 (Eleven Crore only) over the best three (3) years in the last five (5) financial years.

TDS/PDS--C. Qualification Criteria--

The minimum amount of financial resources as liquid asset or working capital or credit line(s) or specific credit commitment or in any combination of them, of the Tenderers shall be Tk 21200000.00 BDT (Two Crore Twelve Lakh Taka Only)

The minimum amount of financial resources as liquid asset or working capital or credit line(s) or specific credit commitment or in any combination of them, of the Tenderers shall be Tk 1,85,00,000.00 BDT (One Crore Eighty-Five Lakh Only).

TDS/PDS--C. Qualification Criteria--

The minimum capacity shall be Tk. 55600000.00 BDT (Five Crore Fifty-Six Lakh Taka Only)

The minimum capacity shall be Tk. 5,50,00,000.00 (Five Crore Fifty Lakh Only).

The following formulae shall be used to calculate the Tender Capacity
Assessed Tender Capacity = (A*N*1.25-B)
Where
A=Maximum value of Works performed in any one year during last five years
N= Completion time of the proposed work in years
B= Value of Existing commitments and works to be completed during the next N Years
For Tenders where the package contains more than one (1) Lot, this qualification requirement shall be mentioned separately for each lot in the package.
Note 1: In case the value of N is less than 12 (twelve) months the value of N shall be considered as 01 (one)

TDS/PDS--C. Qualification Criteria--

A Construction Project Manager, Engineer, and other key staff shall have the following qualifications and experience supported by CVs following the Form PW3-5.

No	Position	Total Works Experience (Years)	Experience in similar works (Years)
1	Project Manager (Contractor’s Representative) -(1 Nos)	10	5
2	Project Engineer -(1 Nos)	5	3
3	Surveyor(1-nos)	5	3
4	Site Engineer (Civil) – (1 Nos)	5	3
5	Site Supervisor -(1 No)	5	3

[qualification of an alternative Construction Project Manager may also be requested]

[for Tenders where the package contains more than one (1) lot, this qualification requirement may be necessary for each lot in the package, subject to the nature of the control required over each package]

A Construction Project Manager, Engineer, and other key staff shall have the following qualifications and experience supported by CVs following the Form PW3-5.

No	Position	Total Works Experience (Years)	Experience in similar works (Years)
1	Project Manager (Contractor’s Representative) -(1 Nos)	10	5
2	Project Engineer -(1 Nos)	5	3
3	Surveyor(1-nos)	3	1
4	Site Engineer (Civil) – (1 Nos)	3	2
5	Site Supervisor -(1 No)	3	2

TDS/PDS--C. Qualification Criteria--

Tenderers shall own or have proven access to hire or lease of the major construction equipment, in full working order as follows:

No	Equipment Type and Charestics	Minimum Number Required	Source of Availability (owned/hired/leased)
1	Excavator	2	(owned/hired/leased)
2	Berge	2	(owned/hired/leased)
3	Geobag Sewing Machine	8	(owned/hired/leased)
4	MIXER Machine	3	(owned/hired/leased)
5	GeneratoR	2	(owned/hired/leased)
6	Forma	1000	(owned/hired/leased)
7	Vibrator	4	(owned/hired/leased)

Tenderers shall own or have proven access to hire or lease of the major construction equipment, in full working order as follows:

No	Equipment Type and Charestics	Minimum Number Required	Source of Availability (owned/hired/leased)
1	Excavator	2	(owned/hired/leased)
2	Berge	2	(owned/hired/leased)
3	Geobag Sewing Machine	6	(owned/hired/leased)
4	MIXER Machine	3	(owned/hired/leased)
5	GeneratoR	2	(owned/hired/leased)
6	Forma	800	(owned/hired/leased)
7	Vibrator	2	(owned/hired/leased)

TDS/PDS--C. Qualification Criteria--

The Nominated Subcontractor(s) named N/A

The Nominated Subcontractor(s) named None.

TDS/PDS--D. Tender Preparation--

Alternatives will not be permitted.
OR
Alternatives will be permitted.
[delete as appropriate]

Alternatives will not be permitted.

TDS/PDS--D. Tender Preparation--

The prices quoted by the Tenderers shall be fixed for the duration of the Contract.

[Price adjustment clauses are usually permitted for Contracts, execution of which will take more than eighteen (18) months from Start Date to Completion Date. The Procuring Entity must consider each Contract on its individual merit; approval of HOPE will be required for Contracts of less than eighteen (18) months . If prices shall be adjustable, the base value of the Indexes including sources and, its corresponding weightings or coefficients for adjustment should be specified in the Appendix to Tender: Table 1.1 and 1.2 and in the Contract]

The prices quoted by the Tenderers shall be fixed for the duration of the Contract.

TDS/PDS--D. Tender Preparation--

TThe required information regarding claims under litigation shall be current or during the last 5.00 years

The required information regarding claims under litigation shall be during the last 3 (three) years.

TDS/PDS--D. Tender Preparation--

The required audit reports on the financial standing, such as profit and loss statements and balance
sheet shall be for the past 2.0 (two) years.

The required audit reports on the financial standing, such as profit and loss statements and balance sheet shall be for the past 02 (two) years.

TDS/PDS--D. Tender Preparation--

The Tender Validity period shall be 120 days.

[normally 60 to 150 days; shorter or longer period may be authorised by HOPE or Authorized officer to suit the requirements of particular Procurement activity].

The Tender Validity period shall be 120 days.

TDS/PDS--D. Tender Preparation--

The amount of the Tender Security shall be Tk. 1850000.00 BDT

The amount of the Tender Security shall be Tk. 18,50,000.00 BDT

TDS/PDS--E. Tender Submission--

For Tender submission purposes only, the Procuring Entity’s address is: The PE is Executive Engineer, Bagerhat WD Division, BWDB, Bagerhat.
Telephone:0468-62195
e-mail address: xen.bwdb.bagerhat@gmail.com
The deadline for submission of Tenders is : Time:14:55 & Date: 13-October-2026

TDS/PDS--G. Contract Award--

The successful Tenderer shall furnish the Performance Security for the due performance of the Contract within 10 working days of issuance of the Notification of Award (NoA).

[• Within seven (7) working days, where the estimated cost does not exceed BDT 50 million (Taka five crore);

• Within ten (10) working days, where the estimated cost exceeds BDT 50 million (Taka five crore) but does not exceed BDT 250 million (Taka twenty-five crore);

• Within fourteen (14) working days, where the estimated cost exceeds BDT 250 million (Taka twenty-five crore).]

The successful Tenderer shall furnish the Performance Security for the due performance of the Contract within 10 working days of issuance of the Notification of Award (NoA).

TDS/PDS--G. Contract Award--

The successful Tenderer shall sign the contract with the Procuring Entity within 21 days of issuance of the Notification of Award (NoA).

[• Within fourteen (14) days, where the estimated cost does not exceed BDT 50 million (Taka five crore);

• Within twenty-one (21) days, where the estimated cost exceeds BDT 50 million (Taka five crore) but does not exceed BDT 250 million (Taka twenty-five crore);

• Within twenty-eight (28) days, where the estimated cost exceeds BDT 250 million (Taka twenty-five crore).]

The successful Tenderer shall sign the contract with the Procuring Entity within 21 days of issuance of the Notification of Award (NoA).

TDS/PDS--G. Contract Award--

The biographical data of the Adjudicator is:

sl no	name	address
1	Md. Mahfuzur Rahman Former Director General, BWDB 01741382792 mmahfuz82@yahoo.com	House#45, Flat #3A, Road # 3/A, Dhanmondi, Dhaka

The biographical data of the Adjudicator is:

sl no	name	address
1	Md. Mahfuzur Rahman Former Director General, BWDB 01741382792 mmahfuz82@yahoo.com	House#45, Flat #3A, Road # 3/A, Dhanmondi, Dhaka

The hourly fee shall be TK 5000(Five Thousand only).

Brief Description of Goods,Works or Service

DB-01

River Bank protection work (Precautionary) from km 14.500 to km 14.800 = 300 m at Debraj of Doiboggohati Sub-Project along the Left Bank of Panguchi River in C/W "Protection of Morrelganj Upazila sadar & Adjacent Areas from Erosion of Panguchi River & Re-excavation/Dredging of Bishkhali River in Bagerhat District " under Bagerhat WD Division, BWDB, Bagerhat.

DB-01

Save As PDF