View IFT /PQ / REOI / RFP / PPS Notice Details
|
Amendment / Corrigendum No. : 1
|
|
| Amendment / Corrigendum Text : | Corrigendum issued as required changes in TDS & PCC. |
| Field Name | Old Value | New Value | ||||||||||||||||||||||||||||||||||||||||||||||||
|---|---|---|---|---|---|---|---|---|---|---|---|---|---|---|---|---|---|---|---|---|---|---|---|---|---|---|---|---|---|---|---|---|---|---|---|---|---|---|---|---|---|---|---|---|---|---|---|---|---|---|
| Document last selling date & time | 13/10/2026 16:50 | 18/10/2026 16:00 | ||||||||||||||||||||||||||||||||||||||||||||||||
| Eligibility of Consultant |
|
As stated in detail in ITT & TDS. |
||||||||||||||||||||||||||||||||||||||||||||||||
| Location(Lot No : 1) | Morrelganj Ferry Ghat | Morrelganj Ferry Ghat, Bagerhat | ||||||||||||||||||||||||||||||||||||||||||||||||
| Opening Date & Time | 14/10/2026 15:00 | 19/10/2026 16:00 | ||||||||||||||||||||||||||||||||||||||||||||||||
| PCC 1. Definitions(aa)Intended Completion Date | The Intended Completion Date for the whole of the Works shall be 2027-06-30 | The Intended Completion Date for the whole of the Works shall be 2027-06-30 | ||||||||||||||||||||||||||||||||||||||||||||||||
| PCC 1. Definitions1.1(qq)StartDate | The Start Date shall be 2026-11-16 | The Start Date shall be 2026-12-02 | ||||||||||||||||||||||||||||||||||||||||||||||||
| PCC 1. Definitions1.1(uu)Works |
|
|
||||||||||||||||||||||||||||||||||||||||||||||||
| PCC 13. Possession of the Site13.1 Possession of the Site |
|
|
||||||||||||||||||||||||||||||||||||||||||||||||
| PCC 2. Interpretation2.5. Sectional completion |
|
|
||||||||||||||||||||||||||||||||||||||||||||||||
| PCC 39. Commencement of Works39.1 Commencement of Works | Commencement Date of Works: 2026-11-01 | Commencement Date of Works:2026-11-25 | ||||||||||||||||||||||||||||||||||||||||||||||||
| PCC 41. Programme of Works41.2 Programme Update | The period between Programme updates is 15 | The period between Programme updates is 30 | ||||||||||||||||||||||||||||||||||||||||||||||||
| PCC 41. Programme of Works41.3 Withhold amount | The amount to be withheld for late submission of an updated Programme is 2000.000 | The amount to be withheld for late submission of an updated Programme is 20000.000 | ||||||||||||||||||||||||||||||||||||||||||||||||
| PCC 64. Payment Certificates64.5 ES obligations withheld maximum Amount Percentage | The maximum amount of payment withheld of forfeited due to failure in compliance with ES Specifications is 0.200 percent of the final Contract Price of the whole of the Works. | The maximum amount of payment withheld of forfeited due to failure in compliance with ES Specifications is 2 percent of the final Contract Price of the whole of the Works. | ||||||||||||||||||||||||||||||||||||||||||||||||
| PCC 82. As-built Drawings and Manuals82.1 As-built drawing date |
|
|
||||||||||||||||||||||||||||||||||||||||||||||||
| PCC 9. Eligibility9.1 Contractor nationality |
|
|
||||||||||||||||||||||||||||||||||||||||||||||||
| PCC 9. Eligibility9.2 Origin Countries |
|
|
||||||||||||||||||||||||||||||||||||||||||||||||
| Last date & time for Tender/Proposal Security Submission | 14/10/2026 14:30 | 19/10/2026 15:30 | ||||||||||||||||||||||||||||||||||||||||||||||||
| Start Date(Lot No : 1) | 01/11/2026 | 02/12/2026 | ||||||||||||||||||||||||||||||||||||||||||||||||
| Closing Date & Time | 14/10/2026 15:00 | 19/10/2026 16:00 | ||||||||||||||||||||||||||||||||||||||||||||||||
| TDS/PDS--B. e-Tender Document (e-TD)-- |
The following are authorised agents/offices of the Procuring Entity for the purpose of issuing the Tender Document: |
For Clarification of Tender Document purposes only, the Procuring Entity's address is: |
||||||||||||||||||||||||||||||||||||||||||||||||
| TDS/PDS--C. Qualification Criteria-- | The minimum specific experience as a Prime Contractor or Subcontractor or ManagementContractor in construction works under public sector of at least onecontract(s) ofConstruction/Repair of revetment/river bank protection work/shore protectionwork/crossbar/Spur/groyne successfully completed within the last 5 years, each with a value of at least Tk. 69500000.00 BDT (Six Crore Ninety-Five Lakh Taka Only).; years counting backward from the date of publication of IFT in the newspaper. |
The minimum specific experience as a Prime Contractor or Subcontractor or ManagementContractor in construction works under public sector of at least one (01) contract(s) of Construction/ Repair of revetment/ river bank protection work/shore protection work/ crossbar/ Spur/ groyne successfully completed within the last 5 years, each with a value of at least Tk. 6,90,00,000.00 (Six Crore Ninety Lakh Only); years counting backward from the date of publication of IFT in the newspaper. |
||||||||||||||||||||||||||||||||||||||||||||||||
| TDS/PDS--C. Qualification Criteria-- | The required average annual construction turnover under public sector shall be greater than Tk. 139000000.00 BDT (Thirteen Crore Ninety Lakh Taka Only) over the best three (3) years in the last five (5) financial years. |
The required average annual construction turnover under public sector shall be greater than Tk. 13,50,00,000.00 (Thirteen Crore Fifty Lakh Only) over the best three (3) years in the last five (5) financial years. |
||||||||||||||||||||||||||||||||||||||||||||||||
| TDS/PDS--C. Qualification Criteria-- | The minimum amount of financial resources as liquid asset or working capital or credit line(s) or specific credit commitment or in any combination of them, of the Tenderers shall be Tk 26500000 .00 BDT(Two Crore Sixty-Five Lakh Taka Only). |
The minimum amount of financial resources as liquid asset or working capital or credit line(s) or specific credit commitment or in any combination of them, of the Tenderers shall be Tk 2,30,00,000 .00 (Two Crore Thirty Lakh Only). |
||||||||||||||||||||||||||||||||||||||||||||||||
| TDS/PDS--C. Qualification Criteria-- | The minimum capacity shall be Tk. 69500000.00 BDT (Six Crore Ninety-Five Lakh Taka Only). |
The minimum capacity shall be Tk. 6,95,00,000.00 (Six Crore Ninety-Five Lakh Only). |
||||||||||||||||||||||||||||||||||||||||||||||||
| TDS/PDS--C. Qualification Criteria-- |
A Construction Project Manager, Engineer, and other key staff shall have the following qualifications and experience supported by CVs following the Form PW3-5.
|
A Construction Project Manager, Engineer, and other key staff shall have the following qualifications and experience supported by CVs following the Form PW3-5.
|
||||||||||||||||||||||||||||||||||||||||||||||||
| TDS/PDS--C. Qualification Criteria-- | The Nominated Subcontractor(s) named n/a |
The Nominated Subcontractor(s) named None. |
||||||||||||||||||||||||||||||||||||||||||||||||
| TDS/PDS--D. Tender Preparation-- | The required information regarding claims under litigation shall be current or during the last 5.00 years. |
The required information regarding claims under litigation shall be during the last 03 (Three) years. |
||||||||||||||||||||||||||||||||||||||||||||||||
| TDS/PDS--D. Tender Preparation-- |
The required audit reports on the financial standing, such as profit and loss statements and balance |
The required audit reports on the financial standing, such as profit and loss statements and balance sheet shall be for the past 02 (two) years. |
||||||||||||||||||||||||||||||||||||||||||||||||
| TDS/PDS--D. Tender Preparation-- | The amount of the Tender Security shall be Tk.2320000.00 BDT. |
The amount of the Tender Security shall be Tk.23,20,000. |
||||||||||||||||||||||||||||||||||||||||||||||||
| TDS/PDS--G. Contract Award-- | The biographical data of the Adjudicator is:
|
The biographical data of the Adjudicator is:
The hourly fee shall be Tk 5000 (Five Thousand only). |
||||||||||||||||||||||||||||||||||||||||||||||||
| Brief Description of Goods,Works or Service | M-03/01 River Bank Protective Work from km 1.797 to km 2.047 = 0.250 km (Remaining Part) at Morrelganj Ferry Ghat area along the Right Bank of Panguchi River in C/W "Protection of Morrelganj Upazila sadar & Adjacent Areas from Erosion of Panguchi River & Re-excavation/Dredging of Bishkhali River in Bagerhat District " Under Bagerhat WD. Division, BWDB, Bagerhat. |
M-03/01 River Bank Protective Work from km 1.797 to km 2.047 = 0.250 km (Remaining Part) at Morrelganj Ferry Ghat area along the Right Bank of Panguchi River in C/W "Protection of Morrelganj Upazila sadar & Adjacent Areas from Erosion of Panguchi River & Re-excavation/Dredging of Bishkhali River in Bagerhat District " Under Bagerhat WD. Division, BWDB, Bagerhat. |