View IFT /PQ / REOI / RFP / PPS Notice Details

Ministry :	Ministry of Water Resources	Division :
Organization :	Bangladesh Water Development Board (BWDB)	Procuring Entity Name :	Habiganj O&M Division
Procuring Entity Code :		Procuring Entity District :	Habiganj
Procurement Nature :	Works	Procurement Type :	NCT
Event Type :	TENDER	Invitation for :	Tender - Single Lot
Invitation Reference No. :	T-1/1531 Date:31-03-22.	Tender/Proposal Status :	Contract Awarded
App ID :	180933	Tender/Proposal ID :	682104

Key Information and Funding Information :

Procurement Method :	Open Tendering Method (OTM)	Budget Type :	Revenue
Source of Funds :	Government

Particular Information :

Project Code :	Not applicable	Project Name :	Not applicable
Tender/Proposal Package No. and Description :	Habi/NDR/W-11/2021-2022 Construction of Boundry wall under Habiganj O&M Division BWDB Habiganj during the year 2021-2022.
Category :	Works for complete or part construction and civil engineering work; Construction work;Building construction work;Engineering works and construction works;Construction work for pipelines, communication and power lines, for highways, roads, airfields and railways; flatwork;Construction work for water projects;Construction works for plants, mining and manufacturing and for buildings relating to the oil and gas industry;Roof works and other special trade construction works
Scheduled Tender/Proposal Publication Date and Time :	06-Apr-2022 10:00	Tender/Proposal Document last selling / downloading Date and Time :	21-Apr-2022 15:00
Pre - Tender/Proposal meeting Start Date and Time :	06-Apr-2022 11:00	Pre - Tender/Proposal meeting End Date and Time :	17-Apr-2022 15:30
Tender/Proposal Closing Date and Time :	21-Apr-2022 15:30	Tender/Proposal Opening Date and Time :	21-Apr-2022 15:30
Last Date and Time for Tender/Proposal Security Submission :	21-Apr-2022 15:00

Information for Tenderer/Consultant :

Eligibility of Tenderer :	All e-Gp enlisted tenderer, who full fills the following requirements: 1) All Bangladeshi citizens, who have valid trade license, Up to date tax clearance certificate, VAT Registration certificate. and not debarred ,not bankrupt. 2) A Tenderer may be a physical or juridical individual or body of individuals, or company, association or any combination of them in the form of a Joint Venture, Consortium or Association (JVCA). 3) A Government-owned enterprise in Bangladesh may also participate in the Tender if it is legally and financially autonomous, it operates under commercial law, and it is not a dependent agency of the Procuring Entity. 4) The Tenderer shall have the legal capacity to enter into the Contract. 5) Tenderers should not be associated, or have been associated in the past, directly or indirectly, with a consultant or any of its affiliates which have been engaged by the Procuring Entity to provide consulting services for the preparation of the design, specifications, and other documents to be used for the procurement of the works to be performed under this Invitation for Tenders. 6) The Tenderer in its own name or its other names or also in the case of its Persons in different names, shall not be under a declaration of ineligibility for corrupt, fraudulent, collusive, coercive, or obstructive practices as stated under ITT. 7) These requirements for eligibility will extend, as applicable, to each JVCA partner and Subcontractor proposed by the Tenderer. 8) The Tenderer with a poor performance, consistent history of litigation or arbitration awards against it shall not be eligible to Tender. 9) The authority reserves the right to increase, reduce or totally cancel the work.
Brief Description of Works :	Construction of Boundry wall under Habiganj O&M Division BWDB Habiganj during the year 2021-2022.
Evaluation Type :	Lot wise
Document Available :	Package wise
Document Fees :	Package wise
Tender/Proposal Document Price (In BDT) :	1000
Mode of Payment :	Payment through Bank
Tender/Proposal Security Valid Up to :	18-Jul-2022
Tender/Proposal Valid Up to :	20-Jun-2022

Lot No.	Identification of Lot	Location	Tender/Proposal security (Amount in BDT)	Tentative Start Date	Tentative Completion Date
1	Construction of Boundary wall under Habiganj O&M Division BWDB Habiganj during the year 2021-2022.	Habiganj	10000	01-May-2022	26-Jun-2022

Procuring Entity Details:

Name of Official Inviting Tender/Proposal :

Md. Shahanaoyz Talukdar

Designation of Official Inviting Tender/Proposal :

Executive Engineer

Address of Official Inviting Tender/Proposal :

Address	: Habiganj.
City	: Habiganj
Thana	: Habiganj Sadar
District	: Habiganj - 3300
Country	: Bangladesh

Contact details of Official Inviting Tender/Proposal :

Phone No	: 0831-52359
Fax No	:

The procuring entity reserves the right to accept or reject all Tenders/Proposals / Pre-Qualifications / EOIs

Note: Bank will update the payment transactions only at the end of the day, so the tenderers should make sure the securities and other payments are made at least one day before the submission date.

Documents

Amendment / Corrigendum No. : 1
Amendment / Corrigendum Text :	There is change in TDS and BoQ which need to be amended.

Field Name

Old Value

New Value

Eligibility of Consultant

All e-Gp enlisted tenderer, who full fills the following requirements:
1) All Bangladeshi citizens, who have valid trade license, Up to date tax clearance certificate, VAT Registration certificate. and not debarred ,not bankrupt.
2) A Tenderer may be a physical or juridical individual or body of individuals, or company, association or any combination of them in the form of a Joint Venture, Consortium or Association (JVCA).
3) A Government-owned enterprise in Bangladesh may also participate in the Tender if it is legally and financially autonomous, it operates under commercial law, and it is not a dependent agency of the Procuring Entity.
4) The Tenderer shall have the legal capacity to enter into the Contract.
5) Tenderers should not be associated, or have been associated in the past, directly or indirectly, with a consultant or any of its affiliates which have been engaged by the Procuring Entity to provide consulting services for the preparation of the design, specifications, and other documents to be used for the procurement of the works to be performed under this Invitation for Tenders.
6) The Tenderer in its own name or its other names or also in the case of its Persons in different names, shall not be under a declaration of ineligibility for corrupt, fraudulent, collusive, coercive, or obstructive practices as stated under ITT.
7) These requirements for eligibility will extend, as applicable, to each JVCA partner and Subcontractor proposed by the Tenderer.
8) The Tenderer with a poor performance, consistent history of litigation or arbitration awards against it shall not be eligible to Tender.
9) The authority reserves the right to increase, reduce or totally cancel the work.

PCC--A. General--

The Site is located at Chunarughat, Habiganj and is defined in drawings No:

The Site is located at Habiganj Sadar, Habiganj and is defined in drawings No:

PCC--A. General--

The Works consist of Tree plantation.

The Works consist of construction of boundary wall.

PCC--A. General--

Possession of the Site to the Contractor shall be given on the following date;

[state date of possession of site]

Possession of the Site to the Contractor shall be given on the following date;

1st week of May,2022.

PCC--B. Time Control--

The Start Date shall be [insert date ]
[it is the last date when the Contractor shall commence execution of the Works under the Contract]

The Start Date shall be 7th May,2022.

PCC--B. Time Control--

The Intended Completion Date for the whole of the Works shall be [insert date]
[to be calculated from the start Date]

The Intended Completion Date for the whole of the Works shall be 25th June,2022.

PCC--B. Time Control--

The Contractor shall submit a Programme for the Works within 7days of signing the Contract.
[usually ten (10) days or may be less]

The Contractor shall submit a Programme for the Works within 7days of signing the Contract.

TDS/PDS--A. General--

The PE is The Executive Engineer, Habiganj O&M Division, BWDB, Habiganj.

The Name of the Tender is:Tree plantation along the right bank of Khowai river from km 27.500 to km 27.700 total 200m in C/W Khowai River System in upazilla: Chunarughat District: Habiganj under Habiganj O&M Division BWDB Habiganj during the year 2021-2022.

Brief Description of the Works:Tree plantation along the right bank of Khowai river from km 27.500 to km 27.700 total 200m in C/W Khowai River System in upazilla: Chunarughat District: Habiganj under Habiganj O&M Division BWDB Habiganj during the year 2021-2022.

Tender Ref: T-1/1531 Date:31-03-22
Lot No(s):1

[if there is more than one(1) lot, individual lots are to be identified in conformity with Section 6: Bill of Quantities]

The PE is The Executive Engineer, Habiganj O&M Division, BWDB, Habiganj.

The Name of the Tender is:Construction of Boundry wall under Habiganj O&M Division BWDB Habiganj during the year 2021-2022.

Brief Description of the Works:Construction of Boundry wall under Habiganj O&M Division BWDB Habiganj during the year 2021-2022.

Tender Ref: T-1/1531 Date:31-03-22
Lot No(s):1

[if there is more than one(1) lot, individual lots are to be identified in conformity with Section 6: Bill of Quantities]

TDS/PDS--C. Qualification Criteria--

The minimum capacity shall be:4.00 Lac

The minimum capacity shall be:4.50 Lac

TDS/PDS--C. Qualification Criteria--

A satisfactory completion of similar works of at least Tk 3.00 Lac unde 1 of contract(s) over a period of 5 years shall be required.

years counting backward from the date of publication of IFT in the newspaper.Similar: Tree plantation/Re-excavation of Khal/River/Construction of Embankment etc.

A satisfactory completion of similar works of at least Tk 3.00 Lac unde 1 of contract(s) over a period of 5 years shall be required.

years counting backward from the date of publication of IFT in the newspaper.Similar: Constuction of boundary wall, construction/Repair of Building etc.

Brief Description of Goods,Works or Service

Construction of Boundry wall under Habiganj O&M Division BWDB Habiganj during the year 2021-2022.

Save As PDF